U.S. CODE

U.S. Code

§ 1816. Construction contracts

(a) Liquidated damages

The Architect of the Capitol may not enter into or administer any construction contract with a value greater than $50,000 unless the contract includes a provision requiring the payment of liquidated damages in the amount determined under subsection (b) of this section in the event that completion of the project is delayed because of the contractor.

(b) Amount of payment

The amount of payment required under a liquidated damages provision described in subsection (a) of this section shall be equal to the product of—

(1) the daily liquidated damage payment rate; and

(2) the number of days by which the completion of the project is delayed.

(1) In general

In subsection (b) of this section, the “daily liquidated damage payment rate” means—

(A) $140, in the case of a contract with a value greater than $50,000 and less than $100,000;

(B) $200, in the case of a contract with a value equal to or greater than $100,000 and equal to or less than $500,000; and

(C) the sum of $200 plus $50 for each $100,000 increment by which the value of the contract exceeds $500,000, in the case of a contract with a value greater than $500,000.

(2) Adjustment in rate permitted

Notwithstanding paragraph (1), the daily liquidated damage payment rate may be adjusted by the contracting officer involved to a rate greater or lesser than the rate described in such paragraph if the contracting officer makes a written determination that the rate described does not accurately reflect the anticipated damages which will be suffered by the United States as a result of the delay in the completion of the contract.

(d) Effective date

This section shall apply with respect to contracts entered into during fiscal year 2002 or any succeeding fiscal year.

Tips